Custom Search
|
|
|
||
 RFP NO. N62742-98-R-1372, BLOCK 17, CONTINUED.
PRICE PROPOSAL SCHEDULE
ITEM 0001
Provide price for the entire work, complete in
accordance with the drawings and specifications,
but not including work indicated or specified below.
LUMP SUM
$________
Est'd Qty
Unit Price
ITEM 0001A
Provide price for removal and disposal
of contaminated fuel/hazardous waste.
900 gals. @ $______/gal. =
$________
TOTAL PRICE FOR ITEM 0001
$________
In the event there is a difference between a unit price and the extended total, the unit price will be
held to be the intended bid and the total recomputed accordingly. If a bidder provides a total but
fails to enter a unit price, the total divided by the specified quantity will be held to be the intended
unit price.
The following clause is incorporated in full text: FAR 52.211-18, VARIATION IN ESTIMATED
QUANTITY (APR 1984).
If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity
of the unit-priced item varies more than 15 percent above or below the estimated quantity, an
equitable adjustment in the contract price shall be made upon demand of either party. The
equitable adjustment shall be based upon any increase or decrease in costs due solely to the
variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation
is such as to cause an increase in the time necessary for completion, the Contractor may
request, in writing, an extension of time, to be received by the Contracting Officer within 10 days
from the beginning of the delay, or within such further period as may be granted by the
Contracting Officer before the date of final settlement of the contract. Upon the receipt of a
written request for an extension, the Contracting Officer shall ascertain the facts and make an
adjustment for extending the completion date as, in the judgement of the Contracting Officer, is
justified.
RFP NO. N62742-98-R-1372
SAMPLE PROPOSAL SCHEDULE
(LUMP SUM WITH UNIT PRICE)
2
|
 
|
|
|
||
